Unfortunately, the listing you're looking for is no longer available.
Similar Listings
REDWOOD CITY SCHOOL DISTRICT REQUEST FOR QUALIFICATIONS AND PROPOSALS (RFQ/P) #S26-002 LEASE-LEASEBACK CONSTRUCTION SERVICES HVAC Upgrades Projects - Increment 3
Redwood City School District ("District") is seeking proposals from qualified persons, firms, partnerships, corporations, associations, or professional organizations to provide constructability review, value engineering, master scheduling, cost estimating, budgeting, and construction services for the development and construction for Increment 3 of the HVAC Upgrades Projects at Roy Cloud and Henry Ford Elementary Schools ("Project"), in accordance with the lease-leaseback structure set forth in Education Code section 17406, et seq.
The Request for Qualifications and Proposals ("RFQ/P"), which includes instructions for its completion, is enclosed for your consideration. Respondents to this RFQ/P shall submit a completed Statement of Qualifications ("SOQ") along with the Proposal (collectively "RFQ/P Packet"). The District will only receive RFQ/P Packets submitted electronically. RFQ/P Packets will be received until 3:00 p.m., Friday, October 30, 2026, only at the following email address nick.olsen@vpcsonline.com. Any RFQ/P Packet that is submitted after this time shall be nonresponsive and returned to the bidder. Each respondent is solely responsible for timely submission of its RFQ/P Packet; the District is not responsible for any technological issues in a respondent's ability to timely submit its RFQ/P Packet or portion thereof.
A mandatory information meeting will be conducted on Monday, October 12, 2026 (School Holiday) at 9:00 A.M. The meeting will be held at Roy Cloud Elementary School, 3790 Red Oak Way, Redwood City, CA 94061. Directly following the meeting at Roy CLoud, we will visit Henry Ford Elementary School, 2498 Massachusetts Ave, Redwood City, CA 94061.
Questions regarding this RFQ/P may be directed to
Nick Olsen, Program Manager, VPCS nick.olsen@vpcsonline.com
Hank Dagenais, Project Manager, VPCS hank.dagenais@vpcsonline.com
Martin Cervantes, Bond Director, RCSD mcervantes@rcsdk8.net
and must be submitted via email by Monday, October 19, 2026 by 2:00 P.M.
This Project is subject to labor compliance monitoring and enforcement of compliance with prevailing wage requirements by the Department of Industrial Relations pursuant to Labor Code § 1771.4, and skilled and trained workforce requirement pursuant to Public Contract Code § 2600. Contractors of all tiers must be currently registered and qualified to perform public work pursuant to Labor Code § 1725.5. All Respondents must be prequalified by the District in accordance with Public Contract Code § 20111.6. First tier electrical, mechanical and plumbing subcontractors must be prequalified prior to the time subcontractor bids are submitted.
RFQ/P SCHEDULE SUMMARY
October 1 & 8, 2026 - Release of RFQ/P Advertisement
October 5, 2026 - RFQ/P packages available at this link; https://drive.google.com/drive/folders/1tZdlYiPo5J_pWKQ1-oAodXFseRpDIzjY?usp=drive_link
Monday, October 12, 2026 (School Holiday) at 9:00 A.M.@ Roy Cloud School - Mandatory In Person Informational Meeting.
Monday, October 19, 2026 by 2:00 P.M. - Last day to receive written questions from Respondents.
Friday, October 23, 2026 by 2:00 P.M. - Last day for District to issue addenda to answer questions/clarifications.
Friday, October 30, 2026 by 3:00 P.M. - Deadline for submissions in response to RFQ/P.
Week of November 2, 2026 Release of shortlist of qualified Respondents and interview notifications.
Week of November 9, 2026 Interviews of qualified Respondents and Notice to selected developer to commence contract negotiation.
Week of November 16, Contract document finalization.
Board Items Due - December 1, 2026
Anticipated Board Approval - December 9, 2026
The District reserves the right to change the dates on the schedule without prior notice. Show more »
Refcode: #IPLSFC01644030
Community Reinvestment Act ("CRA") regulations require a bank that has developed a CRA Strategic Plan (the "Plan") to publish Notice of the Plan and solicit formal written public comment for at least a 30-day period. Western Alliance Bank (the "Bank") hereby provides notice of its intention to submit a CRA Strategic Plan to the Federal Reserve Bank (the "FRB"). Written comments from the public concerning the Plan are encouraged. On or after September 15, 2026, requests for copies of the plan at no charge or comments regarding the Plan should be directed to Craig Robinson, Head of Community Relations, by mail or phone, at 1 East Washington Street, Suite 1400, Phoenix, Arizona 85004, (408) 689-8417. Comments received on or before October 15, 2026 will be considered prior to submission of the Plan for approval to the FRB. Show more »
Refcode: #IPLSFC01622020
NOTICE OF ENTRY OF JUDGMENT ON SISTER-STATE JUDGMENT
Michael R. Farrell (SBN 173831)
Leilee Ghassemi (SBN 351484)
Allen Matkins Leck Gamble Mallory & Natsis LLP
865 South Figueroa Street, Suite 2800
Los Angeles, California 90017
Attorneys for: Chia Tiger
Superior Court of California
County of San Francisco
400 McAllister Street
San Francisco, CA 94102
Case Number: CPF-26-519577
1. TO JUDGMENT DEBTOR: Francesco Lugli
2. YOU ARE NOTIFIED
a. Upon application of the judgment creditor, a judgment against you has been entered in this court as follows:
(1) Judgment creditor (name): Chia Tiger
(2) Amount of judgment entered in this court: $ 175,426.32
b. This judgment was entered based upon a sister-state judgment previously entered against you as follows:
(1) Sister state (name): New York
(2) Sister-state court (name and location): New York County Supreme Court
(3) Judgment entered in sister state on (date): December 15, 2025
(4) Title of case and case number (specify): Chia Tiger v Francesco Lugli, Index No.: 151343/2023
3. A sister-state judgment has been entered against you in a California court. Unless you file a motion to vacate the judgment in this court within 30 DAYS after service of this notice, this judgment will be final.
This court may order that a writ of execution or other enforcement may issue. Your wages, money, and property could be taken without further warning from the court.
If enforcement procedures have already been issued, the property levied on will not be distributed unit 30 days after you are served with this notice.
Michael R. Farrell (mfarrell@allenmatkins.com)
Leilee Ghassemi (lghassemi@allenmatkins.com)
Allen Matkins Leck Gamble Mallory & Natsis LLP
865 South Figueroa Street, Suite 2800
Los Angeles, California 90017
Publication dates: Sep. 4, 11, 18, 25, 2026 Show more »
Refcode: #IPLSFC01616430
- Advertisement -